|
Audit
Feasibilty Studies
|
| Year | Project & Location | US$ |
Rooms |
| 2006/2007 | Westin Hotel, St. Maarten | 125,000,000 |
300 |
| 2000 | Little
Dix Resort (Renovations), British Virgin Islands |
1,000,000 |
80 |
| 2000 | Parrot
Cay Resort, Turks and Caicos Islands |
5,000,000 |
56 |
| 2000 | Le Sport, Tobago | 23,000,000
|
168 |
| 2000 | Le
Sport (Renovations and Extension), Jamaica |
10,000,000
|
150 |
| 2000 | Rendezvous (Extension), St. Lucia | 11,000,000
|
100 |
| 2000 | Cap Juluca (Appraisal), Anguilla | 50,000 |
80 |
| 1995 | Westin Casuarina Hotel, Grand Cayman, Cayman Islands | 53,000,000
|
350 |
| 1992 | Sleep Inn, Grand Cayman, Cayman Islands | 5,000,000 |
115 |
| 1992 | Grand Palazzo Hotel, St. Thomas, United States Virgin Islands | 36,000,000 |
155 |
| 1990 | Marriott Hotel, Grand Cayman, Cayman Islands | 60,000,000 |
210 |
| 1989 | Grand
Pavilion Hotel, Grand Cayman, Cayman Islands |
3,000,000 |
92 |
| 1988 | Spanish
Bay Reef, Grand Cayman, Cayman Islands |
2,500,000 |
46 |
| 1988 | Ramada Turquoise Reef, Providenciales, Turks & Caicos Islands | 22,000,000 |
200 |
| 1987 | Holiday Inn (Renovations), Grand Cayman, Cayman Islands |
5,000,000 |
215 |
| 1987 | Sheraton, Providenciales, Turks & Caicos Islands | 25,000,000 |
231 |
| 1985 | Hyatt Regency Hotel Grand Cayman, Cayman Islands | 27,400,000 |
234 |
| 1983 | Ramada Treasure Island, Grand Cayman, Cayman Islands | 125,000,000
|
290 |
Appartments & Condos
| Year | Project & Location | US$ |
Units |
| 2006/2007 | Careenage Apartments & Marina, Grand Cayman, Cayman Islands | 7,000,000 |
44 |
| 2004/2006 | Anchorage Condos (Hurricane Ivan Refurbishment), Grand Cayman, Cayman Islands | 1,950,000 |
15 |
| 2004/2006 | George Town Villas (Hurricane Ivan Refurbishment), Grand Cayman, Cayman Islands | 4,000,000 |
54 |
| 2000 | Grace Bay Condominium Development, Providenciales, Turks & Caicos Islands | 7,200,000 |
24 |
| 1998 | Gingerbread Apartment, George Town,Grand Cayman, Cayman Islands | 800,000 |
8 |
| 1998 | Red Bay Apartments, Grand Cayman, Cayman Islands | 4,500,000 |
24 |
| 1998 | Palm Heights Drive Apartments, Grand Cayman, Cayman Islands | 1,300,000 |
8 |
| 1998 | Southampton Gardens Townhouses, Grand Cayman, Cayman Islands | 5,000,000 |
30 |
| 1998 | Point Grace - Phase ll, Providenciales, Turks & Caicos Islands | 2,500,000 |
12 |
| 1998 | Provo Golf Club Town Homes - Phase ll, Providenciales, Turks & Caicos Islands | 2,000,000 |
14 |
| 1998 | Provo Golf Club Town Homes - Phase lll, Providenciales, Turks & Caicos Islands | 1,500,000 |
9 |
| 1997 | Point Grace - Phase l, Providenciales, Turks & Caicos Islands | 8,500,000 |
26 |
| 1995 | Provo Golf Club Townhouses, Providenciales, Turks & Caicos Islands | 1,500,000 |
15 |
| 1995 | The Pools at Cayman Kai - Phase l, Grand Cayman, Cayman Islands | 1,200,000 |
4 |
| 1993 | The Avalon, Grand Cayman, Cayman Islands | 6,000,000 |
28 |
| 1992 | Coralstone Club - Phase l, Grand Cayman, Cayman Islands | 2,500,000 |
18 |
| 1992 | Ocean Club - Phase ll, Providenciales, Turks & Caicos Islands | 5,000,000 |
40 |
| 1991 | Ocean Club Condominiums - Phase l, Providenciales, Turks & Caicos Islands | 3,500,000 |
34 |
| 1990 | The Palms, Grand Cayman, Cayman Islands | 3,400,000 |
24 |
| 1989 | Heritage Club, Grand Cayman, Cayman Islands | 2,680,000 |
24 |
| 1989 | South Church Street Court Apartments, Grand Cayman, Cayman Islands | 550,000 |
4 |
| 1988 | Cayman Club, Grand Cayman, Cayman Islands | 6,340,000 |
24 |
| 1988 | The Great House, Grand Cayman, Cayman Islands | 11,500,000 |
26 |
| 1987 | Grand Bay Club, Grand Cayman, Cayman Islands | 1,830,000 |
24 |
| 1986 | Britannia Condominiums, Grand Cayman, Cayman Islands | 12,000,000 |
52 |
| 1985 | Discovery Point - Phase l, Grand Cayman, Cayman Islands | 1,540,000 |
21 |
| 1985 | Admirals Club, Providenciales, Turks & Caicos Islands | 1,000,000 |
12 |
| 1985 | Gardens of the Kai, Grand Cayman, Cayman Islands | 2,400,000 |
16 |
| 1985 | Discovery Point - Phase ll, Grand Cayman, Cayman Islands | 1,750,000 |
24 |
| 1984 | Colonial Club, Grand Cayman, Cayman Islands | 3,000,000 |
22 |
| 1983 | The Retreat - Phase l, Grand Cayman, Cayman Islands | 2,000,000 |
14 |
| 1983 | Turtle Beach, Grand Cayman, Cayman Islands | 950,000 |
23 |
| 1983 | Casa Caribe, Grand Cayman, Cayman Islands | 2,800,000 |
24 |
| 1982 | Poinsettia, Grand Cayman, Cayman Islands | 2,300,000 |
27 |
| 1981 | Tamarind Bay, Grand Cayman, Cayman Islands | 1,400,000 |
28 |
| 1981 | Anchorage Apartments, Grand Cayman, Cayman Islands | 1,400,000 |
11 |
| 1981 | Plantana, Grand Cayman, Cayman Islands | 3,800,000 |
50 |
| 1981 | Plantation Village - Phase ll, Grand Cayman, Cayman Islands | 2,870,000 |
42 |
| 1980 | Villas of the Galleon - Phase ll, Grand Cayman, Cayman Islands | 1,450,000 |
24 |
| 1980 | Cayman Kai Town Houses, Grand Cayman, Cayman Islands | 1,650,000 |
18 |
| 1980 | Drifters Cover, Grand Cayman, Cayman Islands | 990,000 |
11 |
| 1980 | George Town Villas, Grand Cayman, Cayman Islands | 3,900,000 |
54 |
| 1980 | Governor's Sound Apartments, Grand Cayman, Cayman Islands | 1,460,000 |
27 |
| 1980 | Plantation Village - Phase l,Grand Cayman, Cayman Islands | 2,016,000 |
24 |
| 1980 | Villas of the Galleon Phase lll, Grand Cayman, Cayman Islands | 1,269,000 |
28 |
| 1979 | Villas of the Galleon - Phase l, Grand Cayman, Cayman Islands | 1,200,000 |
30 |
| 1979 | The Beachcomber, Grand Cayman, Cayman Islands | 1,750,000 |
24 |
| 1978 | Christopher Columbus, Grand Cayman, Cayman Islands | 2,000,000 |
24 |
| 1977 | Cocoplum, Grand Cayman, Cayman Islands | 600,000 |
12 |
| 1976 | Tarquynn Manor, Grand Cayman, Cayman Islands | 1,800,000 |
24 |
| 1975 | Lime Tree Bay Apartments, Grand Cayman, Cayman Islands | 2,790,000 |
74 |
| 1971 & 1973 | Cayman Court Town Houses, Grand Cayman, Cayman Islands | 750,000 |
12 |
Offices & Commercial
| Year | Project & Location | US$ |
Rentable Sq./Ft |
| 2002 | Insinger, Road Town, Tortola | 2000 |
|
| 2002 | Scotiabank, Road Town, Tortola, British Virgin Islands | 32000 |
|
| 2002 | TCInvest Office Building, Grand Turk, Turks & Caicos Islands | 800,000 |
8,000 |
| 2000 | Hard Rock Café, Grand Cayman, Cayman Islands | 3,000,000 |
10,000 |
| 1998/1999 | Property portfolios with development advice and valuations in St. Lucia, Tobago, Barbados and Anguilla | 300,000,000 |
|
| 1998 | Barclays Bank Building, Tortola, British Virgin Islands | 3,000,000 |
12,700 |
| 1998 | Barclays Bank (Refurbishment), St. Vincent | 1,100,000 |
10,000 |
| 1998 | Barclays Bank (Refurbishment), Grand Turk, Turks & Caicos Islands | 450,000 |
4,400 |
| 1998 | Barclays Bank, New O.B.C., Providenciales, Turks & Caicos Islands | 350,000 |
11,000 |
| 1998 | Barclays Bank, East End, Tortola, British Virgin Islands | 200,000 |
600 |
| 1998 | Ernst & Young Offices (Fit Out), Tortola, British Virgin Islands | 150,000 |
4,300 |
| 1998 | Barclays Bank, Charlestown, Nevis | 150,000 |
3,740 |
| 1998 | Barclays Bank, Grenville, Grenada | 200,000 |
1,250 |
| 1998 | Barclays Bank, St. Maarten | 150,000 |
1,700 |
| 1998 | Marcy Enterprises (BVI) Limited (Office & Retail Development), Tortola, British Virgin Islands | 750,000 |
12,900 |
| 1998 | Barclays Bank, Basseterre, St. Kitts | 400,000 |
7,462 |
| 1998 | Barclays Bank (Refurbishment), Belmopan, Belize | 125,000 |
2,300 |
| 1998 | Dangriga, Belize | 125,000 |
2,300 |
| 1998 | Ugland House - Phase II, Grand Cayman, Cayman Islands | 5,000,000 |
25,000 |
| 1998 | UBS House, Grand Cayman, Cayman Islands | 9,000,000 |
23,000 |
| 1997 | Cayman Water Company Offices, Grand Cayman, Cayman Islands | 1,500,000 |
8,000 |
| 1996 | Barclays Bank (Extension and Refurbishment), St. Johns, Antigua | 3,000,000 |
11,200 |
| 1996 | Barclays Bank (Refurbishment), Anguilla | 1,000,000 |
4,600 |
| 1995 & 2005 | Regis Place, Capital Place, Harbour Place, Queensgate House, Cricket Square, Citrus Grove, Strathvale House (Including all tenants' interiors), Grand Cayman, Cayman Islands | 100,000,000 |
500,000 |
| 1995 | CNB Headquarters, Grand Cayman, Cayman Islands | 7,750,000 |
49,500 |
| 1995 | Elizabethan Square - Phase llll, Grand Cayman, Cayman Islands | 4,400,000 |
30,000 |
| 1994 | Barclays Bank (Extension and Refurbishment), Providenciales,Turks & Caicos Islands | 1,000,000 |
11,600 |
| 1993 | CIBC (Extension), Grand Cayman, Cayman Islands | 4,000,000 |
28,000 |
| 1993 | Ugland House, Grand Cayman, Cayman Islands | 5,000,000 |
25,000 |
| 1993 | Harbour House (Refurbishment), Grand Turk, Turks & Caicos Islands | 200,000 |
20,000 |
| 1993 | Barclays Bank Building, Grand Cayman, Cayman Islands | 7,000,000 |
50,000 |
| 1992 | Piccadilly Centre & Multi Storey Car Park, Grand Cayman, Cayman Islands | 5,122,000 |
20,000 |
| 1991 | Barclays Bank (Renovations),Providenciales, Turks & Caicos Islands | 150,000 |
6,000 |
| 1991 | Provo Power Company, Providenciales, Turks & Caicos Islands | 100,000 |
4,000 |
| 1991 | The Chartered Trust Offices, Providenciales, Turks & Caicos Islands | 100,000 |
2,500 |
| 1990 | Caribbean Utilities Company (Expansion & Redevelopment), Grand Cayman, Cayman Islands | 25,000,000 |
|
| 1986 | Genesis Building,Grand Cayman, Cayman Islands | 2,900,000 |
27,053 |
| 1983 | British American Centre - Phase l,Grand Cayman, Cayman Islands | 1,600,000 |
15,668 |
| 1983 | The Greenery Shopping Centre, Grand Cayman, Cayman Islands | 750,000 |
12,000 |
| 1981 & 1984 | Elizabeth Square, Grand Cayman, Cayman Islands | 3,500,000 |
61,846 |
| 1974 | CIBC Building, Grand Cayman, Cayman Islands | 1,300,000 |
17,406 |
| 1974 | Cash & Carry Supermarket, Grand Cayman, Cayman Islands | 900,000 |
15,000 |
| 1973 | Bank of Nova Scotia, Grand Cayman, Cayman Islands | 1,500,000 |
30,352 |
| 1973 | Supermarket for H.O. Mermen & Co., Grand Cayman, Cayman Islands | 1,500,000 |
25,000 |
| 1972 | Kirk Motors Garage, Grand Cayman, Cayman Islands | 500,000 |
10,000 |
| 1972 | West Wind Building Renovations, Grand Cayman, Cayman Islands | 300,000 |
43,057 |
Civic & Government Projects
| Year | Project & Location | US$ |
| 2002 | Peebles Hospital, Road Town, Tortola, British Virgin Islands | 50,000,000 |
| 2002 | H.Lavity Stoutt Community College Culinary Arts Centre, Tortola, British Virgin Islands | 10,000,000 |
| 2002 | H.Lavity Stoutt Community College Applied Marine Centre, Tortola, British Virgin Islands | 5,000,000 |
| 2002 | Financial Complex, Port Purcell, Tortola, British Virgin Islands | 15,000,000 |
| 2002 | Iris O'Neal Clinic, Virgin Gorda, British Virgin Islands | 50,000 |
| 2002 | Administration Complex, Virgin Gorda, British Virgin Islands | 2,200,000 |
| 2002 | Montserrat Volcanic Observatory, Montserrat | 2,200,000 |
| 2002 | Montserrat Police Station, Montserrat | 1,556,000 |
| 2002 | Montserrat Fire Station, Montserrat | 389,000 |
| 2001 | Lighthouse School and Multi-Purpose Hall, Cayman Islands | 7,800,000 |
| 2000 | Community College Multi-Purpose Hall, Cayman Islands | 2,900,000 |
| 2000 | Treasury Building (Refurbishment), Grand Turk | 500,000 |
| 1999 | Beef Island International Airport, British Virgin Islands | 60,000,000 |
| 1999 | Ministry Building (Refurbishment), Grand Turk | 750,000 |
| 1999 | CID Office, Royal Turks & Caicos Islands Police Force Office (Fit Out), Turks & Caicos Islands | 90,000 |
| 1999 | Turks & Caicos Marine Police Force Office (Fit Out), Providenciales, Turks & Caicos | 45,000 |
| 1998 | Community Centre, Gun Bay, Grand Cayman, Cayman Islands | 600,000 |
| 1998 | Material Management Building, Grand Cayman, Cayman Islands | 1,050,000 |
| 1998 | New Administration Block, Red Bay Primary School, Grand Cayman, Cayman Islands | 1,200,000 |
| 1998 | Grand Turk Police Station, Providenciales, Turks & Caicos Islands | 1,600,000 |
| 1998 | Governor's House, Tortola, British Virgin Islands | 3,000,000 |
| 1998 | British West Indies Collegiate - Phase lll, | |
| 1998 | Providenciales, Turks & Caicos Islands | 500,000 |
| 1998 | Prime Minister's Office, St. John's, Antigua | 2,000,000 |
| 1998 | Beef Island International Airport, British Virgin Islands | 35,000,000 |
| 1997 | Mail Processing Centre, Owen Roberts International Airport, Grand Cayman, Cayman Islands | 1,830,000 |
| 1997 | Cayman Islands Marine Institute, Girls Unit, Grand Cayman, Cayman Islands | 360,000 |
| 1997 | Community College, Multi Purpose Hall, Grand Cayman, Cayman Islands | 1,700,000 |
| 1996 | Savannah Primary School, New Classroom Block, Grand Cayman, Cayman Islands | 1,000,000 |
| 1996 | George Town Hospital, Materials Management Building, Grand Cayman, Cayman Islands | 1,200,000 |
| 1996 | British West Indies Collegiate - Phase ll, Providenciales, Turks & Caicos Islands | 220,000 |
| 1995 | New Offices, Department of Agriculture, Grand Cayman, Cayman Islands | 975,000 |
| 1995 | Firehall (Expansion), Providenciales, Turks & Caicos Islands | 400,000 |
| 1995 | Roman Catholic Church, Grand Turk, Turks & Caicos Islands | 250,000 |
| 1995 | Trafalgar House (Refurbishment), Kingston, Jamaica | 1,300,000 |
| 1995 | Community College Resources Building, Tortola, British Virgin Islands | 25,000,001 |
| 1995 | George Hicks High School, Grand Cayman, Cayman Islands | 2,000,000 |
| 1995 | Northward Prison, Grand Cayman, Cayman Islands | 1,500,000 |
| 1995 | Governor's Office (Refurbishment), Tortola, British Virgin Islands | 200,000 |
| 1994/1995 | Owen Roberts International Airport (Expansion), Grand Cayman, Cayman Islands | 10,000,000 |
| 1994 | Courthouse, Providenciales, Turks & Caicos Islands | 350,000 |
| 1994 | Community College - Phase ll, Grand Cayman, Cayman Islands | 1,000,000 |
| 1994 | Red Bay Primary - Phase ll, Grand Cayman, Cayman Islands | 700,000 |
| 1993 | Waterloo, Government House, Grand Turk, Turks & Caicos Islands | 1,000,000 |
| 1993 | Health Clinic, Providenciales, Turks & Caicos Islands | 1,000,000 |
| 1992 | Red Bay Primary School - Phase I, Grand Cayman, Cayman Islands | 2,450,000 |
| 1992 | Faith Hospital, Cayman Brac, Cayman Islands | 1,800,000 |
| 1992 | Police Hostel, Providenciales, Turks & Caicos Islands | 900,000 |
| 1991 | West Bay Infants School, Grand Cayman, Cayman Islands | 830,000 |
| 1990 | Cayman Dental Clinic, Grand Cayman, Cayman Islands | 560,000 |
| 1988 | Gerrard Smith International Airport Terminal, Cayman Brac, Cayman Islands | 270,000 |
| 1987 | Fire Station, Owen Roberts International Airport, Grand Cayman, Cayman Islands | 1,700,000 |
| 1986 | Harquail Theatre, Cayman National Cultural Foundation, Grand Cayman, Cayman Islands | 1,700,000 |
| 1984 | Temporary Theatre, Cayman National, Cultural Foundation, Grand Cayman, Cayman Islands | 110,000 |
| 1976 | Cayman Racquet Club, Grand Cayman, Cayman Islands | 600,000 |
Residential
Projects
| Year | Project & Location | US$ |
Sq./Ft |
| 2007 | Pereya Residence, Cayman Kai, Grand Cayman, Cayman Islands | 715,000 |
3,454 |
| 2007 | Watkins Residence, Cayman Kai, Grand Cayman, Cayman Islands | 450,000 |
4,500 |
| 2002 | Lot 10 Development, Virgin Gorda, Tortola | 12,500,000 |
20,000 |
| 2002 | Firmenich Residence, Providenciales, Turks & Caicos Islands | 2,500,000 |
8,100 |
| 2001 | Hammer Residence, Vista Del Mar, Grand Cayman, Cayman Islands | 3,000,000 |
11,771 |
| 1999 | Blue Cay, Thompson Cove, Providenciales, Turks & Caicos Islands | 2,100,000 |
4,000 |
| 1998 | Family property portfolio valuations and development consulting, Anguilla | 50,000,000 |
|
| 1998 | Coster Residence, Cayman Kai, Grand Cayman, Cayman Islands | 2,000,000 |
6,500 |
| 1998 | Johnson Residence, Providenciales, Turks & Caicos Islands | 760,000 |
3,200 |
| 1998 | Chilvers Residence, Providenciales, Turks & Caicos Islands | 1,100,000 |
3,000 |
| 1998 | Hoffman Residence, Providenciales, Turks & Caicos Islands | 650,000 |
2,500 |
| 1998 | Katitche Point, Virgin Gorda, British Virgin Islands | 1,500,000 |
4,000 |
| 1998 | O'Neal Residence, Great Mountain, Tortola, British Virgin Islands | 600,000 |
6,500 |
| 1997 | Selamet (Refurbishment), Providenciales, Turks & Caicos Islands | 2,600,000 |
3,000 |
| 1997 | Weze Residence, Providenciales, Turks & Caicos Islands | 400,000 |
2,500 |
| 1997 | Saadet Boathouse, Providenciales, Turks & Caicos Islands | 250,000 |
2,700 |
| 1996 | Callaloo Pavilions, Grand Cayman, Cayman Islands | 592,700 |
3,200 |
| 1995 | Sunrise (Refurbishment), Providenciales, Turks & Caicos Islands | 100,000 |
1,000 |
| 1995 | Sunnyside (Refurbishment), Providenciales, Turks & Caicos Islands | 500,000 |
4,000 |
| 1995 | Cayman House 'V' of Vista Del Mar, Grand Cayman, Cayman Islands | 2,000,000 |
11,600 |
| 1995 | McNulty Residence, Grand Cayman, Cayman Islands | 775,000 |
4,300 |
| 1995 | House at Canal Point, Grand Cayman, Cayman Islands | 600,000 |
3,400 |
| 1995 | Amankai House, Grand Cayman, Cayman Islands | 900,000 |
6,300 |
| 1994 | Villa Carraro, Providenciales, Turks & Caicos Islands | 2,700,000 |
12,000 |
| 1992 | Goodwin Residence, Providenciales, Turks & Caicos Islands | 350,000 |
2,000 |
| 1991 | Sunnyside, Providenciales, Turks & Caicos Islands | 1,500,000 |
4,000 |
| 1991 | Barclays Bank House, Providenciales, Turks & Caicos Islands | 550,000 |
3,000 |
| 1990 | Klein Residence, Providenciales, Turks & Caicos Islands | 450,000 |
25,000 |
| 1990 | Cotton House, Providenciales, Turks & Caicos Islands | 2,000,000 |
6,000 |
| 1989 | Miller Residence, Grand Turk, Turks & Caicos Islands | 350,000 |
3,000 |
| 1985 | Aall & Company House, Grand Cayman, Cayman Islands | 600,000 |
5,000 |
| 1983 | Beaukempkamp House, Grand Cayman, Cayman Islands | 800,000 |
7,000 |
DISPUTE RESOLUTION
| Year | Project & Location |
2007 |
National Housing Corporation of Barbados. CCAS is advising the government owned Housing Corporation on appropriate procurement methods for their low and medium cost housing projects comprising some 293 homes |
| 2007 | Rotherley Construction Inc Barbados. CCAS is advising the Design/ Build contractor on all aspects of procurement for a fast track luxury US$ 65 million luxury apartment complex on the west coast. |
| 2007 | Caribbean Consultants Ltd Barbados. CCAS are advising the builder/ /developer on delays and claims on US$ 35 million Embassy in Bridgetown |
| 2006 | Barbados Investment & Development Corporation and Hafeez Karamath Construction Limited. CCAS is advising BIDC on the Design Build Newton Business Park in Barbados where significant delays have occurred in its completion. |
| 2006 | Trinidad Contractors Limited and Ministry of Works and Transport, Trinidad and Tobago CCAS is advising TCL on the programming and completion of 5# bridges on Toco Main Road funded by IDB. |
| 2006 | Pres-T-Con Limited and Bouygues Batiment Trinidad and Tobago - CCAS advised Pre-T-Con on a claim for the piling contract to the International Waterfront Project in Port of Spain which was successfully settled by negotiation. |
| 2006 | TVA Consultants Limited and Ministry of Finance, Planning and Development, St Vincent - CCAS is providing advice to TVA Consultants Limited in regard to their performance of design consulting services for the Ministry of Finance, Planning and Development in St Vincent on the National Stadium project. CCAS’ work on behalf of TVA includes analyzing TVA’s contractual obligations and providing advice in regard to a claim for wrongful termination. |
| 2006 | Urban Development Corporation of Trinidad and Tobago (Udecott). - CCAS is providing procurement advice to Udecott on a wide range of projects with a total value in excess of US$1billion. |
| 2006 | Trinidad Contractors Limited and National Petroleum Marketing Company Limited - CCAS is advising TCL on Extension of Time and prolongation costs on the construction of a gas station on Tobago |
| 2005 | Pres-T-Con Limited and Bechtel, Trinidad - CCAS provided detailed contract analysis and preparation of opinion on the recovery of additional costs on construction of a jetty for a major LNG project |
| 2004 | Damus Limited and Bechtel, Trinidad - CCAS provided advice to Damus Limited, a specialist piping contractor, on a substantial LNG project located in Trinidad. CCAS’s advice has included subcontract review and assistance in regard to a major work stoppage which has impacted Damus’s work. |
| 2002 – 2004 | Johnston International Limited and Needham’s Point Holdings, Ltd, Barbados – Katz & Stone is providing advice and representation to Johnston International Limited, the main contractor on the Barbados Hilton Hotel project owned by Needham’s Point Holdings Limited. Katz & Stone’s work on behalf of Johnston International Limited includes representing Johnston International Limited in an arbitration initiated against the owner of the project in regard to claims for delay, disruption and changes in the scope of work. The form of contract is the American Institute of Architects. |
| 2003 | Trinidad Contractors Ltd., and Government of Grenada, Grenada - CCAS provided an opinion supporting the recovery of a time extension and time related costs resulting from delays to the Gouyave Sea Defence project, the installation of an armoured rock sea wall, caused by the failure of the Employer to provide accurate design documents. |
| 2003 | Trinidad Contractors, Ltd. and Government of British Virgin Islands, British Virgin Islands – CCAS provided an opinion supporting the recovery of time-related costs under a FIDIC contract resulting from delays to construction of a portion of the works at the Lettsome Airport, B.V.I. Our opinion extended to an analysis of the time-related costs associated with delays to the client’s performance and justification for the recovery of such costs under the contract documents and principles of English construction contract law. |
| 2003 | Roberts Construction & Engineering Co. Ltd., Antigua - CCAS provided an opinion on the recovery of loss and expense and extension of time resulting from delay in the construction of a luxury residence in Jumby Bay, Antigua. |
| 2003 | Damus Limited and VA Tech Voest MCE GmbH, Trinidad - CCAS provided advice to and representation of Damus Limited, a specialist piping contractor on a methanol project located in Port Lisas, Trinidad, in connection with a dispute between Damus and VA Tech Voest MCE GmbH over the application of contract provisions dealing with an overrun in estimated quantities. |
| 2002 | Design Collaborative, Tobago Hilton Hotel, Trinidad and Tobago - CCAS provided advice to the design team on final cost certification and related project close-out issues. The form of contract was American Institute of Architects. |
| 2002 | CO Williams Inc., Grantley Adams International Airport, Barbados - CCAS provided the paving contractor with an opinion on the recovery of Additional costs resulting from delay to and disruption of the works. The form of contract was FIDIC. |
| 2000-2001 | Ace Insurance Headquarters, Bermuda — Working with the owner’s representative, Katz & Stone has provided advice and consultation relative to various construction issues during project performance including contract negotiation and interpretation and the analysis of claims submitted by the main contractor. |
| February 2001 | NH International (Caribbean) Ltd v. ICS (Grenada) Ltd – Provided Expert Opinion on the appointment of the Engineer and the termination of the Contractor’s contract by the Employer. A complex dispute under the terms of a FIDIC contract for the construction of the National Stadium in Grenada, West Indies. Arbitrator ruled in favour of our client NH International (Caribbean) Ltd. |
| December 2001 | Associated Asphalt (UK) Limited/C.O. Williams Construction Limited v The Ministry of Tourism and International Transport Grantley Adams International Airport Barbados –- Opinion on the disruption of the progress of the works by the contractor due to the restricted possession of the site of the works Dispute settled by negotiation. |
| April 2000 | Sea-Land Construction Ltd. and Bermuda Underwater Exploration Institute - Appointed one of three arbitrators by Claimant, a Bermuda-based general contractor, to decide various performance issues arising out of the construction of a museum located in Bermuda and devoted to underwater exploration. Issues included the impact of numerous variations on the project schedule and the contractor’s resulting increased costs. The matter was settled by agreement of the parties after several appearances before the arbitrators and prior to hearings. |
| January 1999 | NH International Ltd./ Emile Elias v. The Government of Jamaica –- Martyn Boud was appointed sole arbitrator by the President of the Institution of Civil Engineers in connection with disputes on the Montego Bay Drainage and Flood Control project. |
| 1998 | Andro Electric Co., Ltd. and Noell, Inc., Grand Cayman — Katz & Stone represented Andro Electric Co., Ltd., the electrical subcontractor, in the resolution of claims against the main contractor on the Caribbean Utilities Company project. |
| June 1998 | Hadsphaltic International Ltd. v Noell Incorporated –- Martyn Boud was appointed mediator by both parties to resolve disputes on the C.U.C. Generating Station project. The matter was settled by the parties following extensive mediation, meetings and negotiation. |
| January 1993 | BCM-Cape v. Pemberton Resorts, Inc. - Appointed as expert witness by BCM-Cape (Turks and Caicos Limited), construction manager, in connection with the arbitration of disputes arising out of construction of the Grand Palazzo Hotel in St. Thomas, U.S. Virgin Islands. Called to testify as an expert by the Claimant on various construction performance issues including the impact of variations on the contractor’s costs and schedule and to prepare a forensic accounting analysis of the employer’s counterclaim seeking to recover major cost overruns. After 43 days of arbitration hearings, the arbitrators awarded Claimant the entirety of its claim, while denying the entirety of the employer’s $12 million counterclaim. |
| 1992 | Burland, Conyers & Marirea and Landmark Restoration, Inc., Bermuda — Katz & Stone represented Burland, Conyers & Marirea in an arbitration arising out of construction of the new Bermuda Airport terminal. The dispute involved the default termination of the specialty contractor for the roof. Working closely with expert roofing consultants, Katz & Stone assisted the main contractor in establishing the validity of the termination and reprocurement costs to complete the defaulted specialty contractors’ work. The form of contract is American Institute of Architects. |
